TERMS AND CONDITIONS

GOVERNMENT

GOVERNMENT COMMERCIAL TERMS AND CONDITIONS COMMERCIAL GOODS - MINIMUM TERMS FOR FFP ORDERS

By accessing this site,
you agree to the following:

 

DZYNE TECHNOLOGIES INCORPORATED TERMS AND CONDITIONS

1. Applicability - The purchase order to which these terms and conditions relate is an offer by DZYNE Technologies Incorporated, a Delaware corporation (“Buyer”) for the purchase of the goods specified on the face of such purchase order (the “Goods”) from the seller on the face of the purchase order (“Seller”) in accordance with and subject to these terms and conditions (the “Terms”; together with the terms and conditions on the face of such purchase order, the “Order”). The Order, together with any documents incorporated herein by reference, constitutes the sole and entire agreement of the parties with respect to the Order, and supersedes all prior or contemporaneous understandings, agreements, negotiations, representations and warranties, and communications, both written and oral, with respect to the subject matter of the Order. The Order expressly limits Seller’s acceptance to the terms of the Order. These Terms prevail over any terms or conditions contained in any other documentation and expressly exclude any of Buyer’s general terms and conditions of sale or any other document issued by Seller in connection with the Order.

2. Acceptance - Buyer and Seller shall be bound by the Order only when Seller: (i) executes and returns the acknowledgment; (ii) commences work pursuant to the Order; (iii) delivers to Buyer any one of the items ordered; or (iv) renders for Buyer any of the services ordered. Buyer may withdraw the Order at any time before it is accepted by Seller. A seller’s confirmation of acceptance, which may or may not include the Seller’s own terms and conditions, will not supersede the terms and conditions of this Order.

3. Delivery Date - Seller shall deliver the Goods in the quantities and on the date(s) specified in the Order or as otherwise agreed in writing by the parties (the “Delivery Date”). Timely delivery of the Goods is of the essence. If Seller fails to deliver the Goods in full on the Delivery Date, Buyer may terminate the Order immediately by providing written notice to Seller and Seller shall indemnify Buyer against any losses, claims, damages, and reasonable costs and expenses directly attributable to Seller’s failure to deliver the Goods on the Delivery Date.

4. Quantity - If Seller delivers more or less than the quantity of Goods ordered, Buyer may reject all or any excess Goods. Any such rejected Goods shall be returned to Seller at Seller’s risk and expense. If Buyer does not reject the Goods and instead accepts delivery of Goods at the increased or reduced quantity, the Price for the Goods shall be adjusted on a pro-rata basis.

5. Delivery Location - All Goods shall be delivered to the address specified in the Order (the “Delivery Location”) during Buyer’s normal business hours or as otherwise instructed by Buyer.

6. Shipping Terms - Delivery shall be made FOB Delivery Location, in accordance with the terms on the Order. Seller shall give written notice of shipment to Buyer when the Goods are delivered to a carrier for transportation. Seller shall provide Buyer all shipping documents, including the commercial invoice, packing list, bill of lading and any other documents necessary to release the Goods to Buyer within two business days after Seller delivers the Goods to the transportation carrier. The Order number must appear on all shipping documents, shipping labels, bills of lading, invoices, correspondence and any other documents pertaining to the Order.

7. Title and Risk of Loss - Title passes to Buyer upon delivery of the Goods to the Delivery Location. Seller bears all risk of loss or damage to the Goods until delivery of the Goods to the Delivery Location.

8. Packaging. All shipments must be packaged to permit efficient handling and provide protection in shipment in accordance with carrier regulations. Buyer's Order, government contract numbers and Seller's packing list number must be shown on all invoices and packing lists. The Order number and Seller's packing list numbers must appear on all bills of lading. Buyer's count or weight will be conclusive on shipments not accompanied by the packing list. Seller shall issue an individual invoice for each shipment. Seller must provide Buyer prior written notice if it requires Buyer to return any packaging material. Any return of such packaging material shall be made at Seller’s expense.

9. Amendment and Modification - No change to the Order is binding upon Buyer unless it is in writing, specifically states that it amends the Order and is signed by an authorized representative of Buyer. Buyer may at any time by written notice make changes within the general scope of the Order in (i) shipping, and packaging instructions, and (ii) the place of delivery and Seller shall promptly proceed with the Order as changed. If any such change increases or decreases the cost of, or the time required for, the performance of the Order, an equitable adjustment in the price or delivery schedule, or both, will be made. Claim for such an adjustment must be made in writing within 30 days from the date the change is ordered, together with a cost breakdown or other facts to support such claim. Where the cost of property made obsolete or excess as a result of a change order is included in Seller's claim for adjustment, Buyer shall have the right to prescribe the manner of disposition of such property.

10. Standards of Work - Seller agrees that the performance of work and services pursuant to the requirements of the Order shall conform to high professional standards.

11. Inspection and Rejection of Nonconforming Goods -

a. All items shall be subject to inspection and test at all practicable times and places, including the period of manufacture, by Buyer and, if there is a Federal Prime Contract number on the face of the Order, the Government, but such inspections and tests shall be so performed as not to unduly delay the work. If such inspections or tests are made on Seller's premises, Seller shall provide without charge reasonable facilities and assistance for the inspectors. All items are also subject to final inspection and acceptance at Buyer's plant within a reasonable time after delivery notwithstanding any prior payments or other inspections.

b. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (i) rescind the Order in its entirety; (ii) accept the Goods at a reasonably reduced price; or (iii) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate the Order for cause. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller’s obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.

12. Price - The price of the Goods is the price stated in the Order (the “Price”). If no price is included in the Order, the Price shall be the price set out in Seller’s published price list in force as of the date of the Order. Unless otherwise specified in the Order, the Price includes all packaging, transportation costs to the Delivery Location, insurance, customs duties and fees and applicable taxes, including, but not limited to, all sales, use or excise taxes. No increase in the Price is effective, whether due to increased material, labor or transportation costs or otherwise, without the prior written consent of Buyer.

13. Payment Terms - Seller shall issue an invoice to Buyer on or any time after the completion of delivery and only in accordance with the Terms. Buyer shall pay all properly invoiced amounts due to Seller within 30 days after Buyer’s receipt of such invoice, except for any amounts disputed by Buyer in good faith. All payments hereunder must be in US dollars.

14. Set-off - Without prejudice to any other right or remedy it may have, Buyer reserves the right to set off at any time any amount owing to it by Seller against any amount payable by Buyer to Seller under the Order.

15. Warranties - Seller warrants to Buyer that for a period of 90 days from the Delivery Date, all Goods will: (a) be free from any defects in workmanship, material and design; (b) conform to applicable specifications, drawings, designs, samples and other requirements specified by Buyer; (c) be fit for their intended purpose and operate as intended; (d) be merchantable; (e) be free and clear of all liens, security interests or other encumbrances; and (f) not infringe or misappropriate any third party’s patent or other intellectual property rights. These warranties survive any delivery, inspection, acceptance or payment of or for the Goods by Buyer. These warranties are cumulative and in addition to any other warranty provided by law or equity. Any applicable statute of limitations runs from the date of Buyer’s discovery of the noncompliance of the Goods with the foregoing warranties. If Buyer gives Seller notice of noncompliance with this Section, Seller shall, at its own cost and expense, promptly replace or repair the defective or nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective or nonconforming goods to Seller and the delivery of repaired or replacement Goods to Buyer. All warranties of Seller, whether created expressly by law or in fact, are incorporated herein by reference and shall include, and are supplemented by, the foregoing express warranties.

16. General Indemnification - Seller shall defend, indemnify and hold harmless Buyer its subsidiaries, affiliates, successors or assigns and their respective directors, officers, shareholders and employees and Buyer’s customers (collectively, “Indemnitees”) against any and all loss, injury, death, damage, liability, claim, deficiency, action, judgment, interest, award, penalty, fine, cost or expense, including reasonable attorney and professional fees and costs, and the cost of enforcing any right to indemnification hereunder and the cost of pursuing any insurance providers (collectively, “Losses”) arising out of or occurring in connection with the products purchased from Seller or Seller’s negligence, willful misconduct or breach of the Terms. Seller shall not enter into any settlement without Buyer’s or Indemnitee’s prior written consent.

17. Patent Indemnity - Except where items are made entirely to Buyer's design, Seller shall, at its expense, hold harmless and defend Buyer, its customers and all parties claiming under buyer against any loss, damage or liability which may be incurred on account of any claim or judgment involving infringement of any U.S. patent, copyright or trademark in the manufacture, use or disposition of any item supplied hereunder. Buyer shall notify Seller promptly of any suit instituted against Buyer and, to the full extent of its ability to do so, permit Seller to defend or settle same. In no event shall Seller enter into any settlement without Buyer’s or Indemnitee’s prior written consent. Nothing in these Terms and Conditions shall be construed or interpreted to limit or in any way restrict the rights of the U.S. Government in regards to data it owns or has a right to use. Seller agrees to flow down the applicable FAR and DFARS clauses to its lower-tier subcontractors as applicable.


18. Tooling and Test Equipment - If the Price is stated to include jigs, dies, fixtures, patterns, or special test equipment and manufacturing aids used in manufacture of the items and drawings thereof (all hereinafter called tooling), such tooling becomes the property of Buyer or its customer immediately upon payment thereof. Tooling shall be used only for the benefit of Buyer or any of its customers, which have acquired the right to use such tooling. Tooling shall be kept in good condition, including necessary replacement, without expense to Buyer. Buyer shall pay for changes of design. Seller shall maintain proper property control records for such tooling and shall promptly furnish Buyer a list thereof on request. Unless otherwise directed by Buyer, upon completion or termination of the Order, Seller shall hold all tooling free of charge for six months subsequent to furnishing an inventory to Buyer with a request for disposition; any such tooling Buyer orders returned shall be delivered FOB Seller's facility, properly crated for domestic shipment. No crating charge is to be included in Seller's quotations unless expressly requested by Buyer.

19. Termination -

a. By written notice to Seller of default, Buyer may terminate the Order in whole or in part if Seller becomes the subject of a proceeding under state or federal law for relief of creditors or makes an assignment for benefit of creditors, or if Seller fails to comply with any of its obligations under the Order. In such event, Buyer may purchase similar items elsewhere, and Seller shall be liable for any reasonable excess costs occasioned Buyer thereby. A waiver of a breach of any provision of the Order shall not constitute a waiver of any other breach. If, after notice of default issued hereunder, it is determined that Seller's failure to perform the Order was due to unforeseeable causes beyond the control and without the fault of Seller, the rights and obligations of the parties shall be governed by paragraph (b) of this Section. The rights and remedies of Buyer under this Section are not exclusive and are in addition to any other rights and remedies afforded Buyer by law or under the Order.

b. Buyer may terminate performance or work under the Order in whole or in part by written notice of termination, whereupon Seller will stop work on the date and to the extent specified in the notice and terminate all orders and subcontracts to the extent they relate to the terminated work. Within 60 days after receipt of such notice of termination, Seller will submit all its claims resulting from such termination. Buyer will have the right to check such claims at any reasonable time or times by inspecting and auditing the records, facilities, and work on materials of Seller relating to the Order. Payment made under this Section constitutes the Buyer's only liability in the event the Order is terminated hereunder.

20. Reproduction Rights - Seller grants Buyer the right to reproduce, use and disclose the reports, drawings, software and other data to be delivered by Seller to Buyer under the Order, but Buyer may not use same to produce items for sale in competition with Seller.

21. Insurance - During the term of the Order and for a period of one year thereafter, Seller shall, at its own expense, maintain and carry insurance in full force and effect which includes, but is not limited to, commercial general liability (including product liability) in a sum no less than $1,000,000 with financially sound and reputable insurers. Upon Buyer’s request, Seller shall provide Buyer with a certificate of insurance from Seller’s insurer evidencing the insurance coverage specified in the Order. The certificate of insurance shall name Buyer as an additional insured. Seller shall provide Buyer with 30 days’ advance written notice in the event of a cancellation or material change in Seller’s insurance policy. Except where prohibited by law, Seller shall require its insurer to waive all rights of subrogation against Buyer’s insurers and Buyer or the Indemnitees.

22. Waiver - No waiver by any party of any of the provisions of the Order shall be effective unless explicitly set forth in writing and signed by the party so waiving. Except as otherwise set forth in the Order, no failure to exercise, or delay in exercising, any rights, remedy, power or privilege arising from the Order shall operate or be construed as a waiver thereof, nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.

23. Confidential Information - All non-public, confidential or proprietary information of Buyer, including, but not limited to, specifications, samples, patterns, designs, plans, drawings, documents, data, business operations, customer lists, pricing, discounts or rebates, disclosed by Buyer to Seller, whether disclosed orally or disclosed or accessed in written, electronic or other form or media, and whether or not marked, designated or otherwise identified as “confidential,” in connection with the Order is confidential, solely for the use of performing the Order and may not be disclosed or copied unless authorized by Buyer in writing. Upon Buyer’s request, Seller shall promptly return all documents and other materials received from Buyer. Buyer shall be entitled to injunctive relief for any violation of this Section. This Section shall not apply to information that is: (a) in the public domain; (b) known to the Seller at the time of disclosure; or (c) rightfully obtained by the Seller on a non-confidential basis from a third party.

24. Assignment - Seller shall not assign, transfer, delegate or subcontract any of its rights or obligations under the Order without the prior written consent of Buyer. Any purported assignment or delegation in violation of this Section shall be null and void. No assignment or delegation shall relieve the Seller of any of its obligations hereunder.

25. Severability - If any term or provision of the Order is invalid, illegal or unenforceable in any jurisdiction, such invalidity, illegality or unenforceability shall not affect any other term or provision of this Agreement or invalidate or render unenforceable such term or provision in any other jurisdiction.

26. Survival - Provisions of the Order which by their nature should apply beyond their terms will remain in force after any termination or expiration of the Order.

27. Relationship of the Parties - The relationship between the parties is that of independent contractors. Nothing contained in the Order shall be construed as creating any agency, partnership, joint venture or other form of joint enterprise, employment or fiduciary relationship between the parties, and neither party shall have authority to contract for or bind the other party in any manner whatsoever. No relationship of exclusivity shall be construed from the Order.

28. Compliance with Law - In performance of the work and shipment of Goods covered by the Order, Seller agrees to comply (and to bear all expense required for compliance) with the Fair Labor Standards Act of 1938, as amended, and regulations thereunder, all applicable provisions of the Walsh-Healy Act, the Buy American Act, the Occupational Safety and Health Act, the Equal Employment Act of 1972 and regulations thereunder, and all other applicable federal, state and local laws, rules, regulations and orders, and agrees to indemnify Buyer against any loss, cost, liability or damage whatsoever, including attorney's fees, which may result from Seller's violation of this Section. Seller agrees that Federal law applies to issues related to FAR and DFARS requirements and thus shall be adjudicated in the proper Federal court system.

29. Disputes - Any dispute arising under this order which is not settled by agreement of the parties may be settled under the American Arbitration Association Commercial Rules; proceedings will be held in Orange County, California. Pending any decision, appeal or judgment in such proceedings, or the settlement of any dispute arising under this order, Seller shall proceed diligently with the performance of the Order in accordance with the decision and instruction of Buyer. Except as may be expressly set for in this document with the U.S. Government Contracting Officer’s express consent, the seller shall not acquire a direct claim or direct course of action against the U.S. Government.

30. Government Contracts - If the face of this Order contains a Government Contract Number, Seller shall provide the Goods and services set forth in the Order in compliance with the “required” and/or “required when applicable” provisions and clauses (collectively, the “Applicable Clauses”) contained in the agreement between Buyer and its customer, which are hereby incorporated by reference and made a part of this Order. Seller agrees that Buyer’s obligations to its customer under these Applicable Clauses flow down to the Seller, such that the Seller shall be obligated to perform this Order under these terms and conditions. The Applicable Clauses are available for Seller’s review upon Seller’s request, and Seller agrees that prior to acceptance of any Order, Seller will carefully read and review the Applicable Clauses. To the extent of any conflict or ambiguity between the Applicable Clauses and the Order, where a provision relates to criteria for quantity or quality of workmanship, materials, equipment, or standard of performance of the Goods or services, the greater quantity and higher quality shall govern. Any reference in the Applicable Clauses to a time period for compliance with reporting or notifications flowed down to Seller shall be adjusted by decreasing the response time by 7 calendar days so as to allow Buyer adequate time to comply at the higher tier.

31. Counterfeit Parts - Seller represents and warrants that only new and authentic materials are used in products to be delivered and that work delivered contains no counterfeit parts. No other material or part, other than a new and authentic part is to be used unless approved in advance in writing.

32. Use of the Work Product - Subcontractor shall not make any use of the work effort produced under the Order unless and until it has received the written permission of Contractor to do so. The withholding of such permission by Contractor is final and conclusive, and not an arbitral question of fact under Section 28 or subject to court review. The title to all such work efforts is in Contractor.

33. Order of Precedence - In the event of any ambiguity or inconsistency in the Order, unless otherwise provided herein, the inconsistency or ambiguity shall be resolved by giving precedence in the following order to the various documents making up the Order:

1. The provisions of the awarded Prime Contract (U.S. Government FAR and DFARS clauses) and/or Subcontract;

2. Applicable Clauses contained in the agreement between Buyer and its customer;

3. General Terms and Conditions contained in this Order; and

4. Any other applicable Terms and Conditions agreed to between Buyer and Seller


 

 
 

MANDATORY FAR/DFARS FLOWDOWN CLAUSES

I. Definitions FAR Subpart 2.101 Reference

As used throughout this Subcontract, the following terms shall have the meanings set forth below:

  • The Subcontract - This executed contractual agreement between DZYNE Technologies Incorporated and Seller listing supplies/services to be furnished and the consideration therefore.

  • Subcontract - The terms “subcontract’, “purchase order,” “order” and “agreement” are interchangeable and include any amendments or change orders.

  • Buyer or Contractor - The party purchasing the supplies/services (DZYNE Technologies Incorporated).

  • Seller, Subcontractor or Vendor - The party that has entered into this subcontract with DZYNE Technologies Incorporated.

  • Government - The United States of America or any department or agency thereof.

  • Head of Agency or Secretary - The Secretary, Under Secretary, Assistant Secretary, or any other head or assistant head of an executive or military department or other federal agency of the Government of the United States of America. The term “his duly authorized representative” means any person or persons or board (other than the Contracting Officer) authorized to act for the Head of the Agency or the Secretary.

  • Procuring Agency - The department of the Government having cognizance of the prime contract.

  • Contracting Officer - The person having cognizance on behalf of the Government of the Prime Contract and any other officer or civilian employee of the Government who is properly designated as the Contracting Officer of the procuring agency. The term includes, except as otherwise provided in this subcontract, any authorized representatives of such Contracting Officer acting within the limits of his authority.

  • Provision - Any part of this subcontract or attachment thereto including, but not limited to, any referenced or incorporated agreement, specification, documentation, data, or any clause(s) or part(s) or combination(s) thereof.

  • Buyer’s Subcontract Representative - Such associate(s) of the Buyer, as the Seller has received notice from the Buyer, as having authority to act for and in behalf of the Buyer.

Therefore, in the Federal Acquisition Regulations (FAR) and Defense Federal Acquisition Regulations Supplement (DFARS) clauses incorporated herein, unless the context of a clause requires otherwise, “Government” means Buyer, “Contracting Officer” means Buyer’s Procurement or Subcontract Representative or his authorized designee, “Contractor” means Seller, and the revision date of each clause shall be the same as contained in the Prime Contract; and “Prime Contract” means the Government contract identified in This Order and under which This Order was issued.

II. Commercial Item Clause

52.244-6 Subcontracts for Commercial Items

As prescribed in 44.403, insert the following clause:

Subcontracts for Commercial Items (Jan 2019)

(a) Definitions. As used in this clause—

“Commercial item” and “commercially available off-the-shelf item” have the meanings contained in Federal Acquisition Regulation 2.101, Definitions.

“Subcontract” includes a transfer of commercial items between divisions, subsidiaries, or affiliates of the Contractor or subcontractor at any tier.

(b) To the maximum extent practicable, the Contractor shall incorporate, and require its subcontractors at all tiers to incorporate, commercial items or non-developmental items as components of items to be supplied under this contract.

(c) (1) The Contractor shall insert the following clauses in subcontracts for commercial items:

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509), if the subcontract exceeds $5.5 million and has a performance period of more than 120 days. In altering this clause to identify the appropriate parties, all disclosures of violation of the civil False Claims Act or of Federal criminal law shall be directed to the agency Office of the Inspector General, with a copy to the Contracting Officer.

(ii) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5), if the subcontract is funded under the Recovery Act.

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017).

(iv) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016), other than subcontracts for commercially available off-the-shelf items, if flow down is required in accordance with paragraph (c) of FAR clause 52.204-21. Reference NIST 800-171 requirements

(v) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(vi) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C.637(d)(2) and (3)), if the subcontract offers further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(viii) 52.222-26, Equal Opportunity (Sept 2015) (E.O.11246).

(ix) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C.4212(a));

(x) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul2014) (29 U.S.C.793).

(xi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C.4212)

(xii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496), if flow down is required in accordance with paragraph (f) of FAR clause 52.222-40.

(xiii)

(A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter 78 and E.O. 13627).

(B) Alternate I (Mar2015) of 52.222-50(22 U.S.C. chapter 78 and E.O. 13627).

(xiv) 52.222-55, Minimum Wages under Executive Order 13658 (Dec2015), if flow down is required in accordance with paragraph (k) of FAR clause 52.222-55.

(xv) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706), if flow down is required in accordance with paragraph (m) of FAR clause 52.222-62.

(xvi)

(A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a) if flow down is required in accordance with 52.224-3(f).

(B) Alternate I (Jan 2017) of 52.224-3, if flow down is required in accordance with 52.224-3(f) and the agency specifies that only its agency-provided training is acceptable).

(xvii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xviii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec2013), if flow down is required in accordance with paragraph (c) of FAR clause 52.232-40.

(xix) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb2006) (46 U.S.C. App.1241 and 10 U.S.C.2631), if flow down is required in accordance with paragraph (d) of FAR clause 52.247-64).

(2) While not required, the Contractor may flow down to subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(d) The Contractor shall include the terms of this clause, including this paragraph (d), in subcontracts awarded under this contract.

(End of clause)

III. Additional Required Clauses – Full Text

All subcontracts over $150,000 (inclusive of options) (at all tiers) except those for commercial items.

52.234-1 Industrial Resources Developed Under Defense Production Act Title III (Dec 1994)

IV. Definitions

a) Title III Industrial Resource - Materials, services, processes, or manufacturing equipment (including the processes, technologies, and ancillary services for the use of such equipment) established or maintained under the authority of Title III, Defense Production Act (50 U.S.C. App. 2091-2093).

b) Title III Project Contractor - A contractor that has received assistance for the development or manufacture of an industrial resource under 50 U.S.C. App. 2091-2093, Defense Production Act.

  • The Contractor shall refer any request from a Title III project contractor for testing and qualification of a Title III industrial resource to the Contracting Officer.

  • Upon the direction of the Contracting Officer, the Contractor shall test Title III industrial resources for qualification. The Contractor shall provide the test results to the Defense Production Act Office, Title III Program, located at Wright Patterson Air Force Base, Ohio 45433-7739.

  • When the Contracting Officer modifies the contract to direct testing pursuant to this clause, the Government will provide the Title III industrial resource to be tested and will make an equitable adjustment in the contract for the costs of testing and qualification of the Title III industrial resource.

  • The Contractor agrees to insert the substance of this clause, including paragraph (e), in every subcontract issued in performance of this contract.

(End of clause)

V. All Subcontracts (at all tiers)

Additional Required Clauses – Incorporated by Reference

The following FAR Clauses are incorporated by reference.

CLAUSE NO. | DESCRIPTION | WHEN REQUIRED

52.203-6 Restrictions on Subcontractor Sales to the Government (when required) Except for commercial items and components.

52.203-7 Anti-Kickback Procedures

(when required) Subcontracts >$150K (at all tiers)

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions

(when required) Flowed to all, subcontracts > $150K must certify.

52.203-12 Limitation on Payments to Influence Certain Federal Transactions

(when required) Flowed to all, subcontracts > $150K must certify.

52.203-13 Contractor Code of Business Ethics and Conduct

(when required) All subcontracts having a value in excess of $5M and performance period > 120 days.

52.204-2 Security Requirements

(when required) All subcontracts (at all tiers) involving access to classified information.

52.204-9 Personal Identity Verification of Contractor Personnel

(when required) When subcontractors are required to have routine physical access to a Federal-controlled information system.

52.214-26 Audit and Records-Sealed Bidding

(when required) All subcontracts (at all tiers) expected to exceed the threshold for submission of cost or pricing data FAR 15.403(a)(1)

52.214-28 Subcontractor Certified Cost or Pricing Data-Modifications-Sealed Bidding

(when required) Required only if in the prime contract.

52.215-2 Audit and Records-Negotiation

(when required) All subcontracts (at all tiers) that exceed the simplified acquisition threshold and that are other than FFP.

52.215-12 Subcontractor Certified Cost or Pricing Data

(when required) All subcontracts expected to exceed the simplified acquisition threshold.

52.215-13 Subcontractor Certified Cost or Pricing Data- Modifications

(when required) All subcontracts expected to exceed the simplified acquisition threshold.

52.215-14 Integrity of Unit Prices

(when required) All subcontracts over the simplified acquisition threshold and for items other than: construction or architect-engineer services; utility services; services where supplies are not required; commercial items; and petroleum products.

52.215-15 Pension Adjustments and Asset Reversions

(when required) All subcontracts that meet the requirements in FAR 15.408(g)

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other than Pensions

(when required) All subcontracts that meet the requirements in FAR 15.408(j)

52.215-19 Notification of Ownership Changes

(when required) All subcontracts that meet the requirements in FAR 15.408(k)

52.219-9 Small Business Subcontracting Plan

(when required) All subcontracts awarded in excess of $700,000 except if for commercial items and components.

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation

(when required) All subcontracts exceeding $150K (at all levels) paragraphs (a) – (d) only.

52.222-21 Prohibition of Segregated Facilities

(when required) All subcontracts subject to the Equal Opportunity clause.

52.222-26 Equal Opportunity

(when required) All subcontracts that are not exempted under Executive Order 11246.

52.222-27 Affirmative Action Compliance Requirements for Construction

(when required) All subcontracts over $10K

52.222-35 Equal Opportunity for Veterans

(when required) All subcontracts of $150K or more

52.222-36 Equal Opportunity for Workers with Disabilities

(when required) All subcontracts over $15K

52.222-37 Employment Reports on Veterans

(when required) All subcontracts $150K and more except for commercial items and components

52.222-41 Service Contract Labor Standards

(when required) All subcontracts subject to the act except those for commercial items and components.

52.224-2 Privacy Act

(when required) All subcontracts subject to the act regarding record systems.

52.225-8 Duty Free Entry

(when required) All subcontracts over $15,000 subject to duty-free purchase of foreign supplies.

52.225-13 Restrictions on Certain Foreign Purchases

(when required) All subcontracts (at all tiers)

52.227-1 Authorization and Consent

(when required) All subcontracts (at all tiers) in excess of the simplified. acquisition threshold.

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement

(when required) All subcontracts (at all tiers) in excess of the simplified acquisition threshold.

52.227-3 Patent Indemnity Alternate III

52.227-9 Refund of Royalties

(when required) All subcontracts (at all tiers) if the royalty payment exceeds $250.

52.227-10 Filing of Patent Applications- Classified Subject Matter

(when required) All subcontracts (at all tiers) that cover or are likely to cover classified subject matter.

52.227-11 Patent Rights – Ownership by the Contractor

(when required) All subcontracts (at all tiers) for experimental, developmental or research work.

52.227-13 Patent Rights – Ownership by the Government

(when required) All subcontracts (at all tiers) for experimental, developmental or research work.

52.227-14 Rights in Data – General

52.228-3 Workers’ Compensation Insurance (Defense Base Act)

(when required) All subcontracts at all tiers

52.228-5 Insurance – Work on a Government Installation

52.229-2 North Carolina State and Local Sales and Use Tax

(when required) Construction only.

52.229-10 State of New Mexico Gross Receipts and Compensating Tax

(when required) All subcontracts (at all tiers) that meet the criteria in FAR 29.401-6(b) (1 through 3).

52.232-16 Progress Payments

(when required) To Small Businesses Only

52.236-13 Accident Prevention

(when required) All subcontracts (at all tiers)

52.237-7 Indemnification and Medical Liability Insurance

(when required) All subcontracts (at all tiers) if the effort is for health care services

52.247-3 Capability to Perform a Contract for the Relocation of a Federal Office and Alternate I (FEB 2006)

(when required) Only if subcontractor performs the move on behalf of the prime.

52.247-63 Preference for U.S.-Flag Carriers

(when required) Only if international air transportation is anticipated.

52.247-64 Preference for Privately Owned U.S.-Flag Commercial Vessels

(when required) All subcontracts (at any tier) unless the prime is at or below the simplified acquisition threshold.

52.248-1 Value Engineering

(when required) All subcontracts $150K or more.

VI. The following DFARS Mandatory Flow Down Clauses through Change Notice 20140528 (5/28/14) are incorporated by reference.

CLAUSE NO. | DESCRIPTION | WHEN REQUIRED

252.203-7001 Prohibition on Persons Convicted of Fraud or other Defense-Contract-Related Felonies

(when required) All first tier subcontracts in excess of the simplified acquisition threshold except those for commercial items or components

252.204-7000 Disclosure of Information

(when required) Under DoD prime contracts

252.204-7012 Safeguarding Covered Defense information and Cyber Incident Reporting

252.208-7000 Intent to Furnish Precious Metals as Government-Furnished Material

(when required) Only if the items being purchased, contain precious metals.

252.211-7000 Acquisition Streamlining

(when required) All subcontracts (at any tier) over $1,500,000

252.219-7003 Small Business Subcontracting Plan (DoD Contracts)

(when required) Under DoD prime contracts

252.222-7000 Restrictions on Employment of Personnel

(when required) All subcontracts (at all tiers)

252.223-7006 Prohibition on Storage, Treatment and Disposal of Toxic and Hazardous Material

(when required) All subcontracts (at all tiers) which require, may require, or permits a subcontractor to treat or dispose of non-DoD owned toxic or hazardous materials.

252.225-7014 Reserved

252.225-7016 Restriction on Acquisition of Ball and Roller Bearings

(when required) All subcontracts (at all tiers) unless commercial items other than ball bearings or items that do not contain ball or roller bearings.

252.225-7019 Restriction on Acquisition of Anchor and Mooring Chain

(when required) All subcontracts (at all tiers) for anchor and mooring chain four inches in diameter and under.

252.225-7025 Restriction on Acquisition of Forgings

(when required) All subcontracts at all tiers unless items purchased contain none of the restricted forging items.

252.225-7032 Waiver of United Kingdom Levies – Evaluation of Offerors

(when required) All subcontracts (at all tiers) where value is over $1 million with an U.K. firm.

252.225-7037 Evaluation of Offers for Air Circuit Breakers

(when required) All subcontracts that involve supplies to be accorded duty-free entry.

252.227-7013 Rights in Technical Data—Noncommercial Items

252.227-7014 Rights in Noncommercial Computer Software and Noncommercial Computer Software Documentation

252.227-7016 Rights in Bid or Proposal Information

(when required) All subcontracts (all tiers)

252.227-7019 Validation of Asserted Restrictions—Computer Software

(when required) All subcontracts (at all tiers)

252.227-7033 Rights in Shop Drawings

(when required) All subcontracts (at all tiers)

252.227-7037 Validation of Restrictive Markings on Technical Data

(when required) All subcontracts (at all tiers) except for commercial items or components.

252.229-7004 Status of Contractor as a Direct Contractor (Spain)

(when required) All subcontracts (at all tiers)

252.239-7016 Telecommunications Security Equipment, Devices, Techniques, and Services

252.244-7000 Subcontracts for Commercial Items and Commercial Components (DoD Contracts)

(when required) All subcontracts (all tiers)

252.246-7003 Notification of Potential Safety Issues

(when required) All subcontracts (all tiers)

252.247-7023 Transportation of Supplies by Sea

(when required) All subcontracts (at all tiers) except for commercial items or components

252.247-7024 Notification of Transportation of Supplies by Sea

(when required) All subcontracts (at all tiers) except for commercial items or components

252.249-7002 Notification of Anticipated Contract Termination or Reduction

(when required) All subcontracts (at all tiers) valued at $150K or more